loader
Page is loading...
Print Logo Logo
Michigan

Michigan Court of Appeals: Construction Lien Can’t Exceed Contract Value

スコット・マーフィー

Scott R. Murphy

Partner
Construction Practice Group Chairperson

The Michigan Court of Appeals held that an arbitrator’s decision to award a contractor consequential damages on a construction lien claim warranted reversal even under the extremely narrow standard of review for arbitration awards. In reaching its decision, the court made the definitive ruling that a contractor may not assert a construction lien for consequential damages beyond the monetary value of the parties’ contract.

In TSP Services, Inc. v. National-Standard, LLC, the contractor’s scope of work included asbestos abatement, demolition of steel structures and disposal of scrap steel as well as other site restoration work for an abandoned industrial facility. The parties’ contract required payment in installments with an aggregate contract price of $414,950, due upon completion of the asbestos abatement. Notably, the contract did not mention the sale of scrap steel or TSP’s potential profits therefrom as compensation under the contract. This fact was significant in the eyes of the appeals court because the arbitration proceeding focused on the profits from the sale of scrap steel as a major component of the contractor’s scope of work.

Because the project experienced significant delays in permitting, the contractor was unable to begin the steel reclamation work. During the delay, the market price for steel declined dramatically and as a result, the value of the contract was diminished significantly. In response to the declining steel prices, the contractor requested an equitable adjustment to the parties’ contract. At the time the contractor requested the equitable adjustment, only 9 percent of the available steel had been removed from the project site. When the parties could not reach an agreement to adjust the contract price, the owner terminated the contractor for cause.

However, the arbitrator ultimately concluded that the owner improperly terminated the parties’ contract and committed the first material breach of the parties’ contract. The arbitrator awarded the contractor a construction lien for $782,496.05 and broke that amount out as follows:

  • $141,083 on the unpaid invoices under the contract
  • $46,557.39 for interest and unpaid invoices
  • $391,809 for lost profits on steel inventory
  • $33,793 for interest on those profits
  • $169,226 in attorneys’ fees

The arbitrator determined that the contractor’s construction lien was valid, and was enforceable against the entire award, including the award for consequential damages for lost profits on steel inventory. Notably, the arbitrator awarded the contractor the full value of all the steel even though the contractor never actually removed the steel from the project site.

Despite the extremely narrow standard of review for arbitration awards under Michigan law, the Michigan Court of Appeals reversed the arbitrator’s award of consequential damages in connection with the lien claim because the value of the lien was nearly double the value of the parties’ contract. In reaching this decision, the appeals court emphasized that under the Michigan Construction Lien Act, the amount of any construction lien cannot exceed the remaining unpaid balance under the contract. See MCL 570.1103(4).

Because the arbitrator approved a construction lien well in excess of the contract value, the award violated the Construction Lien Act. Specifically, the arbitrator approved a lien for $782,469, which is $641,386 greater than the unpaid balance under the contract. According to the appeals court, the arbitrator’s award constituted a clear legal error that would reduce the value of the lien by over $500,000.

In reversing the arbitration award, the appeals court relied upon the Michigan Supreme Court’s decision in Detroit Auto Inter-Insurance Exch v Gavin, which held that judicial interference with an arbitration award is appropriate where the arbitration award contains a clear error of law that if corrected would substantially change the award. The Michigan Court of Appeals granted interlocutory relief because further proceedings on the lien claim would have only further complicated the issues and lead to multifarious litigation.

In summary, the decision in TSP Services, Inc v National-Standard makes it clear that consequential damages are not available under the Michigan Construction Lien Act when they exceed the balance of the parties’ contract.


RELATED ARTICLES

Michigan Court Appoints Receiver to Complete Construction Project

July 17, 2019 | Construction Law, Lien Law, Appeals

Subscribe

Do you want to receive more valuable insights directly in your inbox? Visit our subscription center and let us know what you're interested in learning more about.

View Subscription Center
Trending Connect
We use cookies on this site to enhance your user experience. By clicking any link on this page you are giving your consent for us to use cookies.